Insight

When the Levy Breaks

Tariffs against China on construction materials are capricious, unpredictable, and often spectacularly ill-timed. How can the industry prepare?

How Tariffs on China Hurt U.S. Construction
WF

Warren Friedman

December 21, 2018 10:43 AM

Twice this year—in March and May—President Trump issued proclamations imposing tariffs on American imports of steel (a 25 percent levy) and aluminum (10 percent). Initially, these charges applied only narrowly, but they’ve since been extended to nearly every country with which the U.S. trades.

Also this spring, Trump imposed a 25 percent tariff on a variety of Chinese products, part of a measure to penalize China for its trade practices; as the year has progressed, more Chinese goods have been added.

Most recently, on September 24 the Office of the United States Trade Representative (USTR), at the president’s direction, released a list of roughly $200 billion worth of Chinese imports subject to still more tariffs. They went into effect immediately at 10 percent but will jump to 25 percent on January 1, 2019.

On September 17, a week before, the U.S. Department of Commerce had announced the preliminary determination of its countervailing-duty investigation of the import of Chinese quartz surface products, noting that exporters received subsidies ranging from 34.4 to 178.5 percent. Commerce therefore instructed U.S. Customs and Border Protection to collect cash deposits from importers of these goods; it is scheduled to issue a final determination next January 28.

The construction industry, like any other, is greatly affected by commodity price fluctuations. Typical supply-and-demand cost adjustments are to be expected, and construction companies have a number of mechanisms to deal with them. The imposition of tariffs, however, cannot be planned for, because it represents direct government intervention that makes a nearly immediate impact on the price of the targeted goods. How can the industry cope?

Of prime importance, as contractors and subcontractors enter into new contracts, is to negotiate an appropriate “tariff clause,” or price-escalation provision, that counteracts the effects of such levies. For existing contracts without safety valves, however, recovery is a greater challenge, given that price increases sparked by tariffs are typically part of the contractor’s accepted risk inherent to lump-sum or guaranteed-maximum price contracting. Tariffs’ very nature, though, means some potential avenues for relief nonetheless remain.

Tax Provisions

Construction contracts may contain a provision allowing for recovery because of newly implemented taxes. The Federal Acquisition Regulation (FAR), for example, is incorporated into many federal procurement contracts, and FAR 52.229-3(c) specifically provides that “the contract price shall be increased by the amount of any after-imposed Federal tax, provided the contractor warrants in writing that no amount for such newly imposed Federal excise tax or duty or rate increase was included in the contract price, as a contingency reserve or otherwise.”

Similarly, Section 3.6 of the American Institute of Architects AIA A201 (2017) General Conditions of the Contract for Construction states that “[t]he Contractor shall pay sales, consumer, use, and similar taxes for the Work provided by the Contractor that are legally enacted when bids are received or negotiations concluded, whether or not yet effective or merely scheduled to go into effect.” Under this provision, arguably, if a contractor remains obligated only to pay taxes that are legally enacted when bids are received or negotiations concluded, it is not obligated to pay any such taxes that emerge after the fact—such as Trump’s recent tariffs. In these circumstances, the contractor may be able to shift the burden of the new taxes to the project owner.

Force Majeure

Force-majeure clauses in construction contracts are another means of recovery for tariffs’ price increases, but relief will largely depend on the terms negotiated for force majeure itself.

Generally speaking, the concept refers to an unexpected event that prevents someone from doing or completing a task he or she had agreed to perform, and may excuse the party from having to do so altogether. Many standard construction agreements limit force-majeure recovery merely to an extension of the contract time—and while an extension might help, it certainly won’t solve the price disparities the tariffs impose.

Instead, provided an appropriate force-majeure provision exists, a contractor may be able to argue that its performance should be excused entirely. To succeed under this theory, however, the contractor would be required to prove that the cost increases made performance impossible or commercially impracticable.

Delay Damages

Another means of recovery may be a contract provision entitling a contractor to damages because of an owner-caused delay. This requires the contractor to prove that the owner’s delay in design or material selection prevented the contractor from timely ordering of materials—which got more expensive in the interim once tariffs were imposed. A claim of this sort will necessitate a detailed review of project schedules and an assessment of when materials should (or could) have been ordered.

Other Provisions

Frequently, construction contracts contain provisions that shift risk to other parties (including subcontractors), and these should also be examined to determine whether another party ought to bear the risk of price increases spurred by tariffs. From a practical standpoint, though, in some cases the increases are so significant that enforcement of these terms might lead to a host of other issues, including failed performance.

Ultimately, the starting point for any lawyer should be the negotiation and inclusion of an appropriate price-escalation clause that contemplates price increases resulting from tariffs—but if this is not an option, or if the contract has already been executed, a close look at other provisions may provide avenues for recovery or for excused performance.

-----------

Warren E. Friedman focuses his practice on construction law and real estate counseling and litigation. He places particular emphasis on providing strategic business counseling to his clients designed to prevent costly disputes before they arise. However, when disputes do arise, Mr. Friedman’s extensive litigation experience ensures a cost-effective and aggressive solution. His clients include contractors, construction managers, owner/developers, institutions, lenders, and sureties on both private and public projects. Mr. Friedman also has extensive experience with licensure issues, surety relations, negotiating and drafting various contract documents, monitoring the construction process during construction, regulatory compliance, and counseling clients through project administration.

Related Articles

IN PARTNERSHIP

Heroes Among Men: How Adam Leitman Bailey, P.C. Saved Lives of the Lifesaving


by Rebecca Blackwell

When a 911 Center in New York City was put in danger, Adam Leitman Bailey, P.C. went to work against the unlawful and hazardous actions of a developer whose construction threatened the peace and safety of all who worked for the Fortune 500 company.

Danger construction site no trespassing sign on fence

A Look Ahead


by Jarred Boyer

The future of U.S. rental markets may seem uncertain as we continue to grapple with the after-effects of COVID-19, but renters and landlords alike can look toward a more hopeful few years as inflation already begins to recede and the promise of stabilization is on the horizon.

Paper houses and crane sitting amongst coins and money

Out of the Sky: What Construction Workers Can Do if Injured on the Job


by Justin Smulison

Construction zones with unsafe working conditions have long been the sites of injuries for workers. The Perecman Firm, P.L.L.C. fights for victims in New York City and Long Island.

Advice for Injured Construction Workers

Contracts and Translations


by Christian Ray Pilares

Working with manufacturers in China can be profitable but challenging. Third party services like law firms and translation services can be helpful.

Safeguard Working with Chinese Manufacturers

Property Rights...and Wrongs


by Chad Cooper and Steven S. Kaufman

Winning a legal battle often boils down to finding and targeting the weakest part of an opponent’s case. Four recent real estate disputes in northeast Ohio are good examples.

Strategies for Real Estate Litigation

Wearing a Hard Hat Significantly Reduces Risk of Injury, Death on NYC Construction Sites


by Michele Mirman

Construction Injury Prevention From Hard Hats

Sharpening the Sword: What You Need to Know About CASPA


by Eric B. Smith

How the Contractor and Subcontractor Payment Act (CASPA) can radically change the stakes of how you build. Learn what CASPA means for your construction projects and contract disputes.

How CASPA Impacts Commercial Real Estate

Teamwork and Strategy


by Justin Smulison

In 2018, Block O'Toole & Murphy continued to secure multimillion-dollar results for injured victims and workers.

Block O'Toole & Murphy Gets Results

In the News: Georgia


by Nicole Ortiz

A summary of newsworthy content from Colorado lawyers and law firms.

In the News Georgia 2018

Compliance Confidence


by Jeffrey E. Stone, John Huang, and Michelle Gon

Turning risk into opportunity.

Compliance Confidence

Charlene Barshefky, 2017 Washington D.C. "Lawyer of the Year" for International Trade and Finance Law


by Nathaniel Barr

Ambassador Charlene Barshefsky of WilmerHale.

WilmerHale

Trending Articles

Announcing the 2023 The Best Lawyers in America Honorees


by Best Lawyers

Only the top 5.3% of all practicing lawyers in the U.S. were selected by their peers for inclusion in the 29th edition of The Best Lawyers in America®.

Gold strings and dots connecting to form US map

Announcing the 2022 Best Lawyers® in the United States


by Best Lawyers

The results include an elite field of top lawyers listed in the 28th Edition of The Best Lawyers in America® and in the 2nd Edition of Best Lawyers: Ones to Watch in America for 2022.

2022 Best Lawyers Listings for United States

2021 Best Lawyers: The Global Issue


by Best Lawyers

The 2021 Global Issue features top legal talent from the most recent editions of Best Lawyers and Best Lawyers: Ones to Watch worldwide.

2021 Best Lawyers: The Global Issue

The U.S. Best Lawyers Voting Season Is Open


by Best Lawyers

The voting season for the 31st edition of The Best Lawyers in America® and the 5th edition of Best Lawyers: Ones to Watch® in America is officially underway, and we are offering some helpful advice to this year’s voters.

Golden figures of people standing on blue surface connected by white lines

How To Find A Pro Bono Lawyer


by Best Lawyers

Best Lawyers dives into the vital role pro bono lawyers play in ensuring access to justice for all and the transformative impact they have on communities.

Hands joined around a table with phone, paper, pen and glasses

What the Courts Say About Recording in the Classroom


by Christina Henagen Peer and Peter Zawadski

Students and parents are increasingly asking to use audio devices to record what's being said in the classroom. But is it legal? A recent ruling offer gives the answer to a question confusing parents and administrators alike.

Is It Legal for Students to Record Teachers?

How Palworld Is Testing the Limits of Nintendo’s Legal Power


by Gregory Sirico

Many are calling the new game Palworld “Pokémon GO with guns,” noting the games striking similarities. Experts speculate how Nintendo could take legal action.

Animated figures with guns stand on top of creatures

The Best Lawyers in Australia™ 2024 Launch


by Best Lawyers

Best Lawyers is excited to announce The Best Lawyers in Australia™ for 2023, including the top lawyers and law firms from Australia.

Australian Parliament beside water at sunset

Inflation Escalation


by Ashley S. Wagner

Inflation and rising costs are at the forefront of everyone’s mind as we enter 2023. The current volatile market makes it more important than ever to understand the rent escalation clauses in current and future commercial lease agreements.

Suited figure in front of rising market and inflated balloon

Best Lawyers: Ones to Watch in America for 2023


by Best Lawyers

The third edition of Best Lawyers: Ones to Watch in America™ highlights the legal talent of lawyers who have been in practice less than 10 years.

Three arrows made of lines and dots on blue background

A Celebration of Excellence: The Best Lawyers in Canada 2024 Awards


by Best Lawyers

As we embark on the 18th edition of The Best Lawyers in Canada™, we are excited to highlight excellence and top legal talent across the country.

Abstract image of red and white Canada flag in triangles

8 Different Types of Criminal Defenses in Law


by Best Lawyers

Learn about the different types of criminal defenses available in law, including innocence, self-defense, insanity and more. Protect your rights today.

Silver handcuffs laying on finger printed papers

Wage and Overtime Laws for Truck Drivers


by Greg Mansell

For truck drivers nationwide, underpayment and overtime violations are just the beginning of a long list of problems. Below we explore the wages you are entitled to but may not be receiving.

Truck Driver Wage and Overtime Laws in the US

The Upcycle Conundrum


by Karen Kreider Gaunt

Laudable or litigious? What you need to know about potential copyright and trademark infringement when repurposing products.

Repurposed Products and Copyright Infringemen

Choosing a Title Company: What a Seller Should Expect


by Roy D. Oppenheim

When it comes to choosing a title company, how much power exactly does a seller have?

Choosing the Title Company As Seller

The 2024 Best Lawyers in Spain™


by Best Lawyers

Best Lawyers is honored to announce the 16th edition of The Best Lawyers in Spain™ and the third edition of Best Lawyers: Ones to Watch in Spain™ for 2024.

Tall buildings and rushing traffic against clouds and sun in sky